Checklist of Items to include in the contract with your contractor:
Click the link above for PDF format.
Make sure the contract covers the following items:
Contractor Information
- Contractor (company name)
- Principle contact
- Project manager
- Address
- Telephone (office/business and cell numbers) and Fax numbers
- E-mail address and website
Owner Information
- Owner(s) names
- Address (include buzzer number if different than unit)
- Telephone (office/business and cell numbers) and Fax numbers
- E-mail ________________
- Project address (if different from above)
- Description of Work
- Scope of work, details of materials, if any drawings are available, refer to the drawing.
- Include what the work does not include
- Timing – list project milestones and the target date for completion
- Terms of Payment
- The Contract price is to be calculated as follows (select one):
- Stipulated fixed cost basis (all inclusive) $__________________, plus applicable tax Payments shall be due and payable as outlined in the Payment Schedule.
- Cost plus ______________% of cost, plus applicable tax Payments shall be due on a bi-weekly _______ or monthly ________ basis (check one).
- Cost plus fixed fee of $_______________________, plus applicable tax
- Payment Schedule
- Changes in Work Utilities and Washroom Facilities
- Warranty
- Other Contractors
- Who are they?
- Owner reserves the right to allow separate contracts in connection with the Work or to do certain work by Owner’s own forces as specified in Description of Work.
- Dispute Resolution
The Owner and the Contractor agree that in the event of a dispute as to the interpretation of the Contract or the extent of the Work, the issues shall be submitted to arbitration as agreed to by both parties or under the province’s arbitration statute. - Default by Owner
- Default by Contractor
- Signatures
If the payment method is laid out based on the stage of work, make sure each stage of the job has been achieved and inspected (according to local bylaws) before making the payment for that stage.
It is wise to hold back a percentage of the payment for a short time to ensure the final job meets your expectations. This is an arrangement between you and the contractor. This may not be necessary if you have a good relationship with him.
Related Posts
August 17, 2018
Architect Blog
Modern home with Feng Shui methodology
June 15, 2018
Architect Blog
What you should know and do before renovating your house in Vancouver – Part 2
Invest in a good designer to create the best looking home for you